Exhibit 10.2

ASIC DESIGN AND PRODUCTION AGREEMENT

between

OPEN-SILICON, INC.

490 N. McCarthy Blvd., Suite 220

Milpitas, CA 95035

and

NETLIST, INC.

51 Discovery, Suite 150

Irvine, CA 92618

[***]

Effective Date

1

OPEN-SILICON ASIC DESIGN AND PRODUCTION AGREEMENT

THIS ASIC DESIGN AND PRODUCTION AGREEMENT (this “ Agreement ”) is made and entered as of [***], 2010 (the “ Effective Date ”) by and between OPEN-SILICON, INC. , a Delaware corporation with its principal place of business at 490 North McCarthy Boulevard, Suite 220, Milpitas, California 95035 (“ Open-Silicon ”) and NETLIST, INC. , a Delaware corporation with its principal place of business at 51 Discovery, Suite 150, Irvine, California 92618 (“ Customer ”), for purposes of setting forth the terms and conditions governing the manufacture and sale by Open-Silicon of one or more ASIC devices for Customer, as further specified in one or more Statements of Work (each, a “ Statement of Work ” or “ SOW ”) attached hereto as Exhibit A and incorporated herein.

1.                                       DEFINITIONS.   Any capitalized terms that are used herein shall have the meanings set forth below or, if not set forth below, the meanings ascribed to them in the other exhibits to this Agreement.

1.1           “Delivery Release” means Customer’s authorization to ship a definite quantity of Products on a specified schedule.

1.2           “Design Respin” is a redesign of a Product due to a deficiency in the initial design of the Product, as evidenced in the Prototypes.

1.3           “Intellectual Property Rights” shall mean all intellectual property rights, including, without limitation, patents, copyrights, authors’ rights, mask work rights, trademarks, trade names, know-how and trade secrets, irrespective of whether such rights arise under U.S. or international intellectual property, unfair competition or trade secret laws.

1.4           “IP Provider” is a third party provider of intellectual property and/or the embodiments of such intellectual property, by way of license, sale, or otherwise.

1.5           “Macrocell ” shall mean the hardware implementation of any functions requested by Customer and furnished by Open-Silicon or its suppliers that Open-Silicon makes available for incorporation by Customer into a specified Product. \

1.6           “ Macrofunctions ” shall mean the software implementation of any functions requested by Customer and furnished by Open-Silicon or its suppliers that Open-Silicon makes available for incorporation by Customer into a specified Product.

1.7           “ Netlist ” shall mean the list form in Verilog or other format of a structural circuit implementation describing the basic design building blocks and their logical connections.

1.8           “Product” means an application specific integrated circuit (ASIC) described or referenced in a Statement of Work, and unless otherwise specified, refers to Production Units and Prototypes.

1.9           “Project Technology” means (i) the [***], all [***] files, all [***], any [***], and any [***] developed or created in the performance of this Agreement and (ii) all other information, know-how, data, specifications, designs and other technology, developed or created in the performance of this Agreement, and identified as deliverables under the applicable SOW (or otherwise in a writing signed by both parties) or are included in such deliverables.

2

1.10         “Prototypes” are engineering samples or the preliminary implementations on silicon of a specified Product, which are intended for internal use, and are not yet qualified and approved for production.

1.11         “Prototype Approval” occurs when Customer has completed the Prototype Approval Form attached hereto as Exhibit B-1 , certifying that the Prototypes meet the agreed to specifications.

1.12         “Production Units” means product manufactured after Prototype Approval and Release to Production.  Production Units do not include Prototypes or Risk Product.

1.13         “Project” shall mean the ASIC project specified in the applicable Statement of Work.

1.14         “Purchase Order” is Customer’s document setting forth specific Products ordered and including Delivery Release information.

1.15         “Release to Production” occurs when Customer has completed the Release to Production Form attached hereto as Exhibit B-2 .

1.16         “Risk Product” is Product (other than Prototypes) ordered by Customer pursuant to a Delivery Release for a delivery date occurring before Release to Production.  For the avoidance of doubt, Risk Product is ordered and ordered and purchased at Customer’s risk.

1.17         “Services” shall mean the ASIC design and manufacturing services to be performed by Open-Silicon (or by a third party on behalf of Open-Silicon) as set forth in a Statement of Work, and any related consulting services.

1.18         “Statement of Work” or “SOW” means a document which sets forth the responsibilities and deliverables of each party within the Project.

1.19         “Subcontractor” is a third party (other than an IP Provider) who provides services to a party in furtherance or fulfillment of its obligations to the other party under this Agreement .

1.20         [***] means the occurrence of any of the following: (i) [***] of this agreement by [***] pursuant to [***], (ii) [***] or [***] (which lasts for 30 days) of this Agreement by Open-Silicon [***], (iii) Open Silicon becoming [***] or [***] or under any other [***] or other similar laws, (iv) Open Silicon [***] or otherwise [***] in the [***]; or (v) transition of the [***] to a [***] pursuant to [***] is not completed within [***] of the [***] of the [***] process.

2.                                                                                       ASIC DEVELOPMENT AND PRODUCTION.

2.1           Development Services.  The development activities for Products covered by this Agreement shall be set forth in one or more SOWs developed and mutually agreed to by the parties.  Each SOW shall set forth the responsibilities and deliverables of each party regarding the development of the Products.  Each party will perform its obligations and deliver its deliverables as set forth in and in accordance with the applicable SOW, and each party will cooperate with the other for the timely achievement of Project milestones.  In performing the Services, Open-Silicon shall provide its own personnel, equipment, tools and other materials at its own expense.  Customer will promptly acknowledge the completion of each milestone (at the request of Open-Silicon, such acknowledgement shall be in writing in substantially the form of Exhibit D ). Customer acknowledges and agrees that Open-Silicon’s

3

ability to perform the Services and to deliver its deliverables may be dependant upon Customer’s timely delivering certain deliverables or information as set forth in the applicable SOW.  In the event that Open-Silicon cannot timely meet its development or delivery obligations due late delivery of such Customer deliverables and/or information, the parties shall renegotiate in good faith any affected schedule as reasonably necessary in light of the extent and nature of the delay.

2.2           ECO Process.   Open-Silicon will use [***] to implement Customer’s requests for changes to the SOW and/or the design of the Products (“ Change(s) ”), provided such Changes are technically feasible.  Customer will submit requested Changes in writing.  Open-Silicon will promptly evaluate such requests and inform Customer in writing of the potential effects on the SOW (and the basis for Open-Silicon’s determination), including: (i) effect on the original schedule, (ii) effect on the engineering development charges, (iii) effect on the estimated production unit pricing due to die size, package or other changes, and (iv) other relevant factors.  Any Changes that are mutually agreed to in writing shall be documented in accordance with Open-Silicon’s Engineering Change Order process (“ ECO Process ”) described in Exhibit C . The parties will discuss in good faith any requested Changes and any impacts of pricing and scheduling of such Changes.  Unless Changes are mutually agreed to in writing by the parties, the parties will continue their respective activities under the SOW without making any modifications to the SOW and/or the design of the Products.

2.3           Delivery of Prototypes.   Upon completion of the engineering milestones specified in the SOW, Open-Silicon will manufacture and deliver the Prototype units to Customer in accordance with the SOW. Open-Silicon shall test each Prototype with the test program as specified in the SOW prior to delivery and shall provide all test results to Customer together with the Prototypes (provided, however, that such test results shall not be binding on Customer).  The parties’ activities in such regard will be further defined within the SOW. Customer acknowledges the Prototypes are delivered and intended for evaluation purposes only and are not intended for other use or resale for use in any system or application.

2.4           Prototype Evaluation.  Customer will promptly evaluate the Prototypes and advise Open-Silicon in writing whether the Prototypes conform to agreed upon specifications for the Product, as set forth in the SOW.  The prototype evaluation period shall not exceed [***] after shipment of initial prototypes (the “ Prototype Evaluation Period ”).  If Customer concludes during the Prototype Evaluation Period, that the Prototypes are not conforming, then Customer will submit a written notice of rejection (“ Notice of Prototype Rejection ”) to Open-Silicon describing in reasonable detail the perceived deficiency or nonconformance of the prototype.  If the Customer does not submit a notice of rejection to Open-Silicon during the Prototype Evaluation Period, the Prototypes will be deemed accepted.  Customer may accept the Prototypes prior to the expiration of the Prototype Evaluation Period by signing and submitting to Open-Silicon a Prototype Approval Form attached hereto as Exhibit B-1 .

2.5           Effect of Notice of Prototype Rejection.  If Customer submits a Notice of Prototype Rejection, the Parties will mutually cooperate to determine the source of any Prototypes nonconformance stated in the Notice of Prototype Rejection. Further, Customer and Open-Silicon will cooperate to resolve and, as appropriate, to develop and implement a corrective action plan, to remedy all reported defects.  Open-Silicon shall deliver a corrected version of such Prototype within a reasonable period of time given engineering time and manufacturing lead times.  The process detailed in Sections 2.2, 2.3 and 2.4 shall be repeated until the Prototypes successfully pass Customer’s evaluation in accordance with Section 2.3 (“ Conforming Prototypes ”), and the cost for such repeated procedure shall be borne by Open-Silicon; provided, however, that if a Design Respin is required for any reason other than an error or deficiency resulting from the design services provided by Open-Silicon or its Subcontractors, Customer will be liable for the costs associated with the Design Respin. If Open-Silicon fails to deliver Conforming Prototypes after the foregoing procedure is [***] Open-Silicon shall be deemed to be in material breach of this Agreement and Customer may, in its sole discretion either (i) grant Open-Silicon an [***], or (ii) immediately [***] or the applicable [***] and require a [***] of any [***] to [***] related to such Prototype.

4

2.6           Changes to Functionality or Performance. In the event that Customer desires to change the functionality or performance of the Product (either before or after delivery of Prototypes) and receive new Prototypes prior to Release to Production, Customer and Open-Silicon will develop a new mutually agreed upon SOW or will amend the existing SOW, in accordance with the ECO Process set forth in Section 2.1.

2.7           Risk Product.  Prior to Release to Production, Customer may request the delivery of Risk Product.  The provision by Open-Silicon of Risk Product to Customer will be subject to the terms of this Section 2.6, as well as such other terms and conditions separately agreed to by the parties.  CUSTOMER ACKNOWLEDGES AND AGREES THAT RISK PRODUCT IS MANUFACTURED SOLELY AS AN ACCOMODATION TO CUSTOMER AND WILL BE PROVIDED “AS IS” AND “WITH ALL FAULTS”, WITHOUT ANY WARRANTY OF ANY KIND, WHETHER EXPRESS, IMPLIED OR STATUTORY, INCLUDING BUT NOT LIMITED TO THE IMPLIED WARANTIES OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, TITLE, AND NON-INFRINGEMENT OF THIRD PARTY RIGHTS, AND QUALITY, AND ALL WARRANTIES ARISING FROM A COURSE OF DEALING, USAGE, OR TRADE PRACTICE .   Customer assumes full responsibility and liability for Risk Product, including but not limited to all work in process (WIP) without regard to issues of design or performance.

2.8           Acceptance Prior to Manufacturing.  Open-Silicon will not commence production of Production Units until Customer confirms the Release to Production of the Product by signing and submitting a Release to Production Form attached hereto as Exhibit B-2 , and submitting a purchase order for the units as set forth in Section 4.1.

2.9           Escrow.  Within [***] after the Effective Date, Open-Silicon and Customer will enter into a technology escrow agreement (the “ Escrow Agreement ”), with terms reasonably satisfactory to both parties, with [***] or another escrow agent designated by Customer (“ Escrow Agent ”).  Thereafter, Open-Silicon will deposit with the Escrow Agent the following items on a regular basis ( i.e. , as soon as they are developed or created) during the term of this Agreement: (a) all Project Technology developed, created or obtained by or for Open-Silicon, and (b) such additional [***] in [***] possession necessary or useful to enable a [***] or other relevant vendors to [***] and collectively with the Project Technology, “Escrow Materials” Open-Silicon will use commercially reasonable efforts to ensure that the Escrow Materials deposited with the Escrow Agent are kept current.  Customer shall be responsible for any and all payments to the Escrow Agent associated with such Escrow Agreement; provided that in the event of [***] (other than [***] of this Agreement by [***] pursuant to [***]) Open-Silicon will be responsible to pay, or if already paid by Customer, reimburse Customer for, any such costs.  The parties agree, and the Escrow Agreement will specify, that upon receipt by the Escrow Agent of a written notice from [***] that a [***] has occurred, all Escrow Materials will immediately be released and delivered to Customer.  Open-Silicon hereby grants to Customer a perpetual, irrevocable, fully paid-up, royalty-free, non-exclusive, sublicenseable, worldwide, license; (i) to use, copy, reproduce, modify, translate, and make derivative works based on the [***] and (ii) distribute the [***] (or derivatives thereof) to a [***] to have such [***] for the Products and use such [***].  [***] hereby covenants that it will [***] until the [***].  [***] further agrees that Project Technology created or developed [***] hereunder will not be used by [***] to perform the Services on [***] to [***] unless and until [***] or a [***] occurs.

5

3.                                                                                       COMPENSATION FOR DESIGN SERVICES.

3.1    NRE Fees.  Design engineering charges for Product development are set forth in the applicable SOW and are based on the specifications and assumptions therein (“ NRE Fees ”).  Customer will pay the NRE Fees in accordance with the milestone schedule set forth in the applicable SOW.  Unless otherwise specified in the SOW, Open-Silicon will invoice Customer upon successful completion of each such milestone (which shall be determined in accordance with the acceptance criteria and procedure set forth in this Agreement and the applicable SOW).  Payments relating to a milestone, the completion of which has been acknowledged by Customer, are [***].  Payment of NRE Fees will be payable within [***] after Customer’s receipt of the invoice.  If Customer requests changes to the specifications or the SOW that increase the cost of the development, Open-Silicon will evaluate the requested changes and notify Customer in writing of the increased costs that Customer will be required to pay, in accordance with Section 2.1.

3.2  Taxes.  Each pa rty shall bear and be responsible to pay any tax (and any related interest or penalty), however designated, legally imposed upon it with respect to the design and development activities contemplated by this Agreement.

4.                                                                                       FORECASTING AND ORDERS FOR PRODUCTION UNITS.

4.1           Forecasts.  Following Release to Production, Customer shall provide Open-Silicon, on a monthly basis, good-faith, non-binding rolling forecasts of its purchase requirements for the Production Units, [***] following the month in which the forecast is submitted (each, a “ Forecast ”). Any Forecasts provided by Customer are for planning purposes only and do not constitute a Delivery Release or other commitment by Customer. Customer shall have no obligation with respect to the purchase of Products under this Agreement until such Products are specified in an issued Purchase Order that contains specific Delivery Release dates for specific Products.

4.2           Purchase Orders.  Customer may order Production Units from time to time by issuing a purchase order to Open-Silicon for such units.  Open-Silicon shall confirm its receipt of such purchase order within [***] in a written acknowledgment to Customer.  Such purchase order shall not request delivery inconsistent with the applicable lead time (as set forth in the applicable SOW) without a line item for the appropriate expedite fees. Customer’s purchase orders and Forecasts may [***] for Production Units set forth in the applicable SOW.  Open-Silicon will not be obligated to make shipments [***]. Any Customer purchase order received by Open-Silicon that complies with the foregoing (a “ Purchase Order ”) shall be binding on Customer and Open-Silicon.  All Purchase Orders and Open-Silicon ’s acknowledgements shall be subject to and expressly limited to the terms and conditions of this Agreement and the applicable SOW and any terms or conditions contained in Purchase Orders or acknowledgements (or in other documents issued by either party) that are inconsistent with or in addition to the terms and conditions contained in this Agreement or the applicable SOW shall be of no force or effect, regardless of any failure of Open-Silicon or Customer to object to such terms or conditions, unless expressly accepted in writing by both parties.

4.3           Supply Commitment .  During the term of this Agreement, Open-Silicon agrees to supply to Customer one-hundred percent (100%) of Customer’s requirements for the Production Units, as specified in Purchase Orders that are not in excess of one hundred and fifty percent (150%) of the then-current Forecast.  Notwithstanding the foregoing, Customer understands that yields for Production Units are subject to fluctuations; therefore, Customer will accept delivery of and accept as full performance: (a) plus five percent (5%) or (b) minus ten percent (10%) of the total quantity ordered, with price adjusted for the quantity actually delivered.

6

5.                                       CANCELLATION AND RESCHEDULING OF ORDERS.

5.1           Cancellation.  Upon notice to Open-Silicon, Customer may cancel any Purchase Order or portion thereof at any time, subject only to the applicable cancellation fees set forth below:

Notwithstanding the above, Open-Silicon shall use commercially reasonable efforts to mitigate any damages or expenses it may incur due to Customer’s cancellation of a Purchase Order (or a portion thereof) by redeploying the Production Units ordered in such Purchase Order to other Purchase Orders of Customer, and Customer’s payment obligation under this Section shall be reduced accordingly.  For purposes of this Section 5.1, “delivery date” with respect of any Purchase Order or portion thereof which has been rescheduled under Section 5.2 shall be deemed to mean the delivery date prior to any rescheduling; provided, however, that any rescheduling of more than thirteen (13) weeks prior to the delivery date shall be deemed a new Purchase Order with a new delivery date.

5.2           Rescheduling. Each Purchase Order may be deferred by Customer no more than [***] time and by no more [***], subject to the terms of this Section 5.2.  Customer acknowledges and agrees that the right to defer or reschedule an order will be subject to the scheduling flexibility of the foundry.  Moreover, Customer agrees that, in the event that Customer requests to reschedule an order as permitted by this Section 5.2, Customer shall be responsible for reimbursing any costs incurred by Open-Silicon as a result of such rescheduling.  Notwithstanding the foregoing, any Purchase Orders with scheduled delivery dates beyond the applicable lead time may be rescheduled by Customer at any time upon written notice to Open-Silicon, provided that [***] shall be [***] incurred by Open-Silicon as a result of accommodating Customer’s request.

5.3           Process Discontinuance by Foundry.  If for any reason, Open-Silicon’s third party foundry supplier discontinues a process, Open-Silicon shall give Customer written notice thereof [***] prior to the last date on which Customer can place an order for Production Unit(s) to be affected by such process discontinuance, and will use its diligent efforts to provide Customer with longer than [***] notice of same.  If such foundry discontinues or is expected to discontinue a process, Open-Silicon shall [***] to transition the manufacturing of Products to a replacement foundry (as designated by Customer and agreed in the SOW or an ECO thereto) and shall provide such replacement foundry with all information (including, without limitation, [***]), cooperation and assistance [***] to effect a smooth and seamless transition.

6.                                       Title and Delivery.

6.1           Deliveries.  All shipments to delivery destinations are made [***] at the [***]. All Products shall be deemed accepted by Customer upon delivery at point of shipment, subject to the Limited Product Warranty set forth in Section 10.  Title to Production Units and risk of loss pass to Customer, or in the case of a Drop Shipment (as defined below), to the receiving party of the shipment (unless such receiving party is serving as Customer’s agent, in which event, title and risk of loss will pass to Customer), upon [***]. In the absence of written instructions from Customer, all Products shall be packed and prepared for shipment in a manner that: (i) follows good commercial practice; (ii) is acceptable to common carriers for shipment at the lowest rate; and (iii) is adequate to ensure safe arrival.  Open-Silicon shall mark all containers with Purchase Order number, lot tracking information, date of shipment, and Customer’s and Open-Silicon’s names, provided in the event that any shipments are made to Customer’s customers (“ Drop Shipments ”), upon Customer’s request, Open-Silicon’s name will be omitted from the containers.  Shipment of Production Units may originate from either Open-Silicon or its Subcontractors or authorized distributors.

7

6.2           Delivery Timeframes.  Open-Silicon will deliver Products in accordance with the delivery dates set forth in Customer’s Purchase Order.  In the event that Production Units ordered in a Purchase Order are delivered late solely due to Open-Silicon’s (excluding its Subcontractors’) delay, Customer will be entitled to deduct from the payments otherwise due to Open-Silicon for such Purchase Order an amount equal to [***] of the total amount of such payments for each week the shipment is late, [***] provided, however, that if the delayed Production Units are delivered to Customer within [***] of the scheduled delivery date, such deduction will be waived.  Without limiting the generality of the foregoing, Open-Silicon will give Customer prompt notice if it reasonably expects a delay in meeting a delivery date or that only a portion of the Products will be available for shipment to meet a delivery date, and Open-Silicon will specify the reasons therefor.  For partial shipments, Open-Silicon will ship the available Products unless directed by Customer to reschedule a shipment. Customer may specify a delivery destination other than its own premises (e.g., Drop Shipment) in order to facilitate delivery directly to its customers. Open-Silicon does not require that delivery be made directly to Customer. For the avoidance of doubt, Customer will be responsible for all costs relating to shipment.

6.3           Early Deliveries.   If Products are delivered more than [***] in advance of the Delivery Dates, Customer may, at its option, either return the Products at Open-Silicon’s expense or keep the Products with payment due as provided in this Agreement.

6.4           Die Banking.  Open-Silicon will provide die banking services to Customer in accordance with the terms and conditions of Exhibit E (“ Die Banking ”). Customer shall order sufficient material be held in die bank to assure continued supply of product within its Forecast.

7.                                       PRODUCTION UNITS PRICING AND PAYMENT.

7.1           Pricing.  Product pricing is set forth in the SOW.  Both parties acknowledge and agree that pricing will not be known until die size is fixed and actual performance frequency and yield of the design is established.  If die size increases or performance/yield is marginal, then Open -Silicon may in good-faith increase pricing in accordance with such changes and to the extent that such price increase shall be reasonable

7.2           Payment.  Unless otherwise agreed, payment terms are [***] from receipt of invoice by Customer. For overdue invoices that are not reasonably disputed by Customer, Customer will pay Open-Silicon interest on the overdue amount at a rate of [***] for each month or part of a month (or the maximum rate allowed by law, whichever is less) that the payment is overdue.  For the avoidance of doubt, for Product invoices, Open-Silicon will invoice Customer upon Product shipment, unless shipment is not made (at Customer’s request), in which event, Open-Silicon will invoice Customer when such Product is ready for shipment.  Unless otherwise instructed by Open-Silicon in writing, all amounts payable to Open-Silicon shall be paid by company check, tendered to such address as Open-Silicon shall designate in an invoice or other notice. Should the parties agree that payments will be made by wire transfer, then Customer shall instruct the paying financial institution to route all domestic wire transfers via FEDWIRE).

7.3           Taxes.  Customer is responsible for and will pay any tax on Production Units.  The prices specified in each applicable quote and/or SOW excludes all duties, taxes and excises and specifically excludes value-added tax (VAT) relating to Production Units.  Open-Silicon shall separately state such taxes if it is required by law to collect such taxes, and Customer agrees to pay such amounts.  The parties will reasonably cooperate to take advantage of benefits provided by any tax treaties.

8

8.                                       TERM.

This Agreement shall commence as of the Effective Date and, subject to Section 0 below and unless earlier terminated in accordance with Section 9 (“Termination”), shall remain in force for a period of ten (10) years, except that Sections 2 and 3 will expire two (2) years after the Effective Date.

9.                                       TERMINATION.

9.1           Termination for Cause.  Either party may terminate this Agreement and/or any or all SOWs upon at least thirty (30) days prior written notice if the other party materially breaches any term or condition hereof and fails to cure the breach within the notice period.  The parties acknowledge that any breach of Sections 4.2 or 7.1 shall be deemed a material breach of this Agreement.

9.2           Termination for Infringement.  Open-Silicon may, upon written notice to Customer, suspend its obligations under an SOW in respect of certain Products where Open-Silicon reasonably believes, after good faith discussions with Customer, that a third party suit or action brought against Open-Silicon and/or Customer alleging that the design, manufacture, or sale of such Products violates the intellectual property rights of the third party has merits.  A suspension under this Section 9.2 that continues for more than nine (9) months shall be deemed a termination of the SOW for such Products.

9.3           Termination for Business Discontinuity.  Either party may terminate this Agreement and/or any or all SOWs in the event that the other party (a) becomes insolvent, otherwise unable to pay its debts as they mature, makes an assignment for the benefit of creditors, or files, or has filed against it (which is not dismissed in thirty (30) days), any claim for an action in bankruptcy or under any other debtor, insolvency, liquidation, or other similar laws, or (b) dissolves, or otherwise ceases doing business in the ordinary course.

9.4           Effect of Termination.  Upon termination, each party will return to the other, or at the other party’s request, destroy (and certify in writing as to such destruction), all Confidential Information in such party’s possession provided by the other party, provided that (i) in the event that there is any dispute arising out of or relating to this Agreement or the termination thereof, each party will be permitted to retain such information as may be relevant to resolution of that dispute but use such information solely in the resolution of the dispute and not for any other purpose, including but not limited to, any commercial use, and when such dispute is resolved, each party will return the retained Confidential Information to the other party; (ii) Open-Silicon will be permitted to retain such information as is necessary for Open-Silicon to perform its surviving obligations under this Agreement; and (iii) Customer will be permitted to retain such information as is necessary for Customer to perform its surviving obligations or exercise surviving rights under this Agreement. Customer remains liable to pay Open-Silicon for Products and Services received (and accepted, if applicable) through the respective date of termination, and any applicable cancellation charges hereunder. In the event that termination is by Customer pursuant to Sections 9.1 or 9.3, the rights granted in Section 13.5 with respect to any IP Provider technology of Intellectual Property Rights shall be transferred and deemed to be direct from IP Providers to Customer, and Open-Silicon hereby appoints Customer to act as its attorney-in-fact to provide notice of the events in Section 9.1 or 9.3 to such IP Providers in order to effect such transfer. The following sections will survive any expiration or termination of this Agreement: Section 1 (“Definitions”); Section 2.6 (“Risk Product”) (solely with respect to the warranty disclaimer), Section 2.8 (“Escrow”); Section 3 (“Compensation for Design Services”) (solely with respect to amounts incurred

9

upon or prior to expiration or termination); Section 7 (“Production Units Pricing and Payment”); Section 0 (“Effect of Termination”); Section 10 (“Limited Product Warranty; Disclaimer”) (solely with respect to the warranty disclaimers); Section 11 (“Limitation of Liability”); Section 12 (“Confidentiality and Publicity”); Section 12.5 (“Intellectual Property Ownership; Licensing”) (except for Section 13.3); Section 14 (“Indemnification”); Section 17 (“Governing Law”); and Section 18 (“Miscellaneous”).  Notwithstanding anything to the contrary, upon any termination or expiration of this Agreement, Customer shall be permitted to sell all remaining inventory of Products in Customer’s possession, and to retain all Prototypes and related design information to permit providing maintenance and support services to its customers.

10.                                LIMITED PRODUCT WARRANTY; DISCLAIMER.

10.1         Limited Product Warranty.  Open-Silicon warrants solely to Customer that Production Units delivered hereunder will [***] approved by Customer and, if properly used, will be [***] for [***] following the date of receipt of the Production Units by Customer. Except as expressly set forth in this Agreement (or an SOW), Open-Silicon makes no warranty with respect to any Services, Prototypes, or Risk Product.  Open-Silicon makes no warranty to any third parties.

10.2         Remedy.  If any Production Unit furnished by or for Open-Silicon fails to conform to the warranty provided in Section 10.1 (“ Limited Product Warranty ”), Open-Silicon’s sole and exclusive liability and Customer’s sole and exclusive remedy will be, at Open-Silicon’s option and expense, to promptly repair or replace the Production Unit, or if repair or replacement is not technically feasible, refund to Customer an amount equal to the price paid for any such Production Unit which fails during the applicable warranty period, provided that: (a) Customer notifies Open-Silicon in writing during the warranty period indicated above that such Production Unit is defective and furnishes an explanation of the deficiency; (b) upon Open-Silicon’s request, such Production Unit is returned, either to Open-Silicon’s service facility or to such other facility designated by Open-Silicon, at Open-Silicon’s risk and expense; and (c) the claimed deficiencies exist and were not caused by accident, misuse, neglect, improper installation, improper testing or unauthorized alteration or repair (all of which will operate to void the warranty provided herein).  If such Production Unit is defective, and Open-Silicon elects to repair or replace it, the transportation charges for the repaired or replaced Production Unit from Open-Silicon to Customer within the USA will be paid by Open-Silicon.  For all other locations, the Limited Product Warranty excludes all costs of shipping, duty, customs clearance, and other related charges.  A repaired or replaced Production Unit will continue to be warranted for the longer of [***] from the original shipment date of the defective Production Unit or [***] after Customer receives the replacement or repaired Production Unit.  All Production Units returned to Open-Silicon shall be returned in accordance with Open-Silicon’s return material authorization procedure. IN NO EVENT WILL OPEN-SILICON BE LIABLE FOR ANY OTHER COSTS ASSOCIATED WITH THE REPAIR OR REPLACEMENT OF PRODUCTS, INCLUDING LABOR, INSTALLATION, OR OTHER COSTS INCURRED BY CUSTOMER AND, IN PARTICULAR, ANY COSTS RELATING TO THE REMOVAL OR REPLACEMENT OF ANY PRODUCTS SOLDERED OR OTHERWISE PERMANENTLY AFFIXED TO ANY PRODUCT, ASSEMBLY, OR COMPONENT.  THE REMEDY SET FORTH IN THIS SECTION 10.2 (“REMEDY”) IS CUSTOMER’S SOLE AND EXCLUSIVE REMEDY IN THE EVENT OF ANY CLAIM UNDER THE LIMITED PRODUCT WARRANTY PROVIDED IN SECTION 10.1 .

10.3         Disclaimer. OPEN-SILICON NEITHER ASSUMES NOR AUTHORIZES ANY PERSON TO ASSUME FOR IT ANY OTHER LIABILITY.  OPEN-SILICON DISCLAIMS ALL LIABILITIES ARISING FROM ANY SERVICES PROVIDED BY A THIRD-PARTY (OTHER THAN OPEN-SILICON’S SUBCONTRACTORS OR FOUNDRY) OR THE USE OR INCORPORATION IN DESIGN PROVIDED BY CUSTOMER OF ANY PRODUCTS PROVIDED BY A THIRD PARTY, INCLUDING WITHOUT LIMITATION, ANY [***].  EXCEPT AS SPECIFICALLY PROVIDED IN THIS AGREEMENT: (A) ALL [***] (AS WELL AS [***]) ARE PROVIDED [***] AND [***] AND [***], AND (B) [***] WITH RESPECT TO THE [***], INCLUDING BUT NOT LIMITED TO [***] OR ANY [***] OUT OF ANY [***].

10

10.4         Third Party Technology.  Customer will be responsible for all third party technology provided or requested by Customer to be included in the Product to ensure that such technology is compatible with, and suitable for, Customer’s intended purposes and applications.

11.                                LIMITATION OF LIABILITY.

11.1         Consequential Damages Disclaimer. EXCEPT WITH RESPECT TO BREACH OF [***] AND LIABILITY ARISING UNDER SECTIONS 14 (“INDEMNIFICATION”), IN NO EVENT WILL EITHER PARTY OR ITS SUPPLIERS BE LIABLE FOR ANY INCIDENTAL, PUNITIVE, INDIRECT, OR CONSEQUENTIAL DAMAGES WITH RESPECT TO PERFORMANCE OF ITS OBLIGATIONS UNDER THIS AGREEMENT, INCLUDING WITHOUT LIMITATION LOST PROFITS, INTERRUPTION OF BUSINESS, OR COST OF PROCUREMENT OF ANY SUBSTITUTE GOODS OR SERVICES, REGARDLESS OF WHETHER SUCH PARTY HAS ADVANCE NOTICE OF THE POSSIBILITY OF SUCH DAMAGES.

11.2         Damages Limitation. [***] , IN NO EVENT WILL EITHER PARTY’S TOTAL CUMULATIVE LIABILITY TO THE OTHER PARTY ARISING OUT OF OR RELATED TO THIS AGREEMENT EXCEED THE HIGHER OF (A) THE AMOUNTS PAID OR PAYABLE BY CUSTOMER TO OPEN-SILICON UNDER THIS AGREEMENT, AND (B) AN AMOUNT EQUAL TO THE NRE FEES PAID OR TO BE PAID BY CUSTOMER UNDER THIS AGREEMENT.

11.3         Indemnity.  IN NO EVENT OTHER THAN AS STATED IN SECTION 14 (“INDEMNIFICATION”) WILL OPEN-SILICON BE OBLIGATED TO INDEMNIFY CUSTOMER OR ANY THIRD PARTY WITH RESPECT TO ANY CLAIM ARISING OUT OF OR RELATED TO THIS AGREEMENT.

11.4         Limitations Essential.  THE PARTIES ACKNOWLEDGE THAT THESE LIMITATIONS ON POTENTIAL LIABILITIES WERE AN ESSENTIAL ELEMENT IN SETTING CONSIDERATION UNDER THIS AGREEMENT AND THAT, IN THE ABSENCE OF SUCH LIMITATIONS, THE ECONOMIC TERMS OF THIS AGREEMENT WOULD BE SUBSTANTIALLY DIFFERENT.  LIABILITY FOR DAMAGES SHALL BE LIMITED AND EXCLUDED, EVEN IF ANY EXCLUSIVE REMEDY PROVIDED FOR IN THIS AGREEMENT FAILS OF ITS ESSENTIAL PURPOSE.

12.                                CONFIDENTIALITY AND PUBLICITY.

12.1         Confidential Information.  “Confidential Information” means all information, trade secrets, technology and other materials disclosed or otherwise made available by one party (the “ Discloser ”) to the other party (the “ Recipient ”), whether before, on or after the Effective Date, (i) in a tangible form marked “Confidential”, “Proprietary” (or with similar legend), (ii) in intangible form or orally and expressed as being confidential at the time of disclosure and confirmed as being confidential in a writing delivered to Recipient within thirty (30) days after initial disclosure, or (iii) under circumstances indicating it is confidential or proprietary.  Confidential Information may be owned by a third party, including a Subcontractor or IP Provider.  Neither party will disclose this Agreement any SOW or their terms, to any third party without the specific, written consent of the other.  Without limiting the foregoing, Project Technology shall be deemed Confidential Information of Customer.  Customer acknowledges that Project Technology may include Confidential Information of Open-Silicon.

11

12.2                         Duties in Respect of Confidential Information.

(a)            Recipient agrees not to use Confidential Information or disclose such Confidential Information except as expressly permitted under this Agreement or as expressly agreed in writing by the Discloser.  Each party shall use Confidential Information disclosed to it solely as permitted under this Agreement.  Subject to the following, Recipient agrees to not disclose Confidential Information except to those employees and contractors of Recipient who have agreed to be bound by confidentiality obligations not less protective than that contained in this Agreement. Recipient has the right to use and disclose Confidential Information reasonably in connection with the exercise of its rights or performance of its obligations under this Agreement, subject to confidentiality obligations no less protective of such Confidential Information as the terms and conditions contained in this Agreement.  Recipient shall exercise the same degree of care to prevent unauthorized use or disclosure of Confidential Information as it takes to preserve and safeguard its own confidential information of similar importance, but in any event, no less than a reasonable degree of care.  Notwithstanding any other provision of this Agreement or any SOW, Open-Silicon’s provision to Customer of anything which contains confidential information or materials of third parties is conditioned on Open-Silicon’s receipt of documentation showing that such third parties permit Customer to receive such confidential information or materials.

(b)            Open-Silicon agrees not to, directly or indirectly (including, without limitation, through Subcontractors), engage in any design or manufacture of products or technology that are Similar to the products for the following companies and their affiliates: [***].  Notwithstanding the provisions of Section 12.2(b), licensing of software and/or technology that Open-Silicon makes generally available shall not be deemed a violation of this provision even if such software and/or technology is used by one of the enumerated companies or their affiliates in products Similar to the Products. As used in this Section 12.2(b), “Similar” means identical to, substantially similar to, or comprising the same form, fit and function as, the Products.

12.3                         Compelled Disclosure.   If disclosure of Confidential Information is required by applicable law: (i) the Parties shall use all legal means available to minimize the disclosure to third parties of the Confidential Information; (ii) the Recipient compelled to make disclosure shall inform the Discloser at least ten (10) business days in advance of the disclosure or, if such notice is impossible, as soon as possible; and (iii) the Recipient compelled to make disclosure shall make reasonable efforts to give the Disclosure a reasonable opportunity to review and comment upon the disclosure, and any request for confidential treatment or a protective order pertaining thereto, prior to making such disclosure, provided that it is not impracticable to do so.

12.4                         Exceptions.   The Recipient shall be relieved of its duties in respect of specific Confidential Information to the extent that any such information: (a) falls into the public domain or becomes publicly known through no fault of Recipient (or its personnel or Subcontractors); (b) becomes known to Recipient, without restriction, from a third party through no breach of trust or an obligation of confidentiality; and/or (c) was independently developed by Recipient without use of the Confidential Information and by employees or contractors of Recipient who had no access to any Confidential Information of Discloser and have not been involved in performance of this Agreement.  The burden of proof of the existence of an exception shall be on Recipient. The Parties may disclose this Agreement and SOWs in confidence to their respective legal counsel, accountants, bankers, and other similar advisors, and financing sources, including potential acquirers or merger partners, as necessary in connection with obtaining services from such third parties or the negotiating of an acquisition or merger.

12.5                         Publicity.   Neither party may use the other party’s name or trademarks in any type of advertisement materials, web sites, press releases, interviews, articles, brochures, business cards, project reference or client listings without the other’s prior written consent except as may be required by law.

12

13.                                Intellectual Property Ownership; Licensing.

13.1         Ownership of Pre-Existing Technology.   Other than the rights expressly granted or assigned in this Section 12.5, Open-Silicon or its licensors will own and retain all Intellectual Property Rights in any [***] and [***] alone and jointly with others, prior to the Effective Date, or [***] independently of performing any Services for Customer, including, without limitation: (i) all [***], (ii) all [***], and (iii) all modifications to such [***].  Customer or its licensors shall own and retain all Intellectual Property Rights in all technology [***], including, without limitation, [***].

13.2         Project Technology .  Customer shall solely and exclusively own all Project Technology and Open-Silicon hereby irrevocably assigns, and agrees to assign, to Customer all right, title and interest, including all Intellectual Property Rights, that Open-Silicon may have in and to any Project Technology.  Customer agrees that Project Technology created or developed by Open-Silicon hereunder will not be used by Customer to [***] to a [***] unless and until [ ***] or a [***].

13.3         Mask Ownership. [***] shall own the masks produced in connection with the performance of this Agreement (including any SOW) and all [***], subject to [***] of any Project Technology [***] or [***].  [***] agrees that such masks shall not be used for any purpose other than [***] unless otherwise agreed [***].  [***] shall destroy such [***] and certify to [***] the destruction thereof.  Effective upon a [***] hereby (a) authorizes [***] and agrees to execute any [***] and (b) grants [***] a [***] (with the right to [***]) to [***] and [***] any products created using such masks.

13.4         Development License . [***] hereby grants to [***], for the term of this Agreement, a [***] Intellectual Property Rights in the Project Technology and [ ***] to [***] the Project Technology and [***] solely to [***] under the Agreement.

13.5         License to Customer .  If Open-Silicon incorporates any [***] (including any technology provided by IP Providers) in any [***], Open-Silicon hereby grants, under any of Open-Silicon’s [***] therein (including rights licensed to Open-Silicon from IP Providers), to Customer [***] to (a) [***] and [***] (including [***]and [***]), and to [***] and [***] any products or services; and (b) [***] and [***] such [***].

13.6         No Implied Licenses.  Except as expressly set forth in this Agreement or any separate license agreement, the parties do not, directly or by implication, by estoppel or otherwise, grant to each other any rights or licenses, and neither party shall have any ownership rights in any intellectual or tangible property of the other.  Any rights not expressly granted hereunder are retained by their respective owner(s).

14.                                INDEMNIFICATION.

14.1         Indemnification by Open-Silicon. Subject to the Limitation of Liability in Section 11.2 and subject to Section 14.2 (“Exclusions from Indemnifications by Open-Silicon”), Open-Silicon will defend or settle any third party claim, action, suit or proceeding brought against Customer based upon a claim that the Services or Production Units, alone and not in combination with any other product or service, constitute a direct infringement of any patent (in effect as of the Effective Date) or copyright issued under the laws of United States, Canada, European Union, Iceland, Norway, Switzerland, India, Israel, Taiwan, Hong Kong, Japan, Australia, or New Zealand, or misappropriation of any trade secret recognized as such under the Uniform Trade Secret laws, and will pay all damages and costs finally awarded against Customer in connection with such claim. Customer will: (i) promptly notify Open-Silicon in writing of any such suit or proceeding, (ii) provide Open-Silicon with sole control over the defense or settlement of any such claim or action; and (iii) provide reasonable information and

13

assistance in the defense or settlement of any such claim or action. Customer may participate in any such suit or proceeding through counsel of its choice at Customer’s own expense; provided that the costs associated with Customer’s counsel shall not be deemed damages or costs for purposes of Open-Silicon’s indemnity hereunder. Open-Silicon shall obtain Customer’s prior written consent, which consent shall not be unreasonably withheld, to any settlement of any third party claim, action, suit or proceeding, except if the settlement is only for monetary damages and contains a full release of Customer from the claim.

14.2         Exclusions from Indemnification by Open-Silicon .   Open-Silicon will not be liable for any expenses, damages, costs or losses arising out of or resulting from any suit or proceeding based upon a claim of intellectual property infringement to the extent arising from: (a) Open-Silicon’s or its Subcontractor’s use of or compliance with Customer’s designs and specifications, or any Customer-furnished Technology, or (b) any alleged infringement based on protocols established by standards bodies.

14.3         Indemnification by Customer.  Subject to the Limitation of Liability in Section 11.2 and subject to Section 14.4 (“Exclusions from Indemnifications by Customer”) , Customer will defend or settle any third party claim, action, suit or proceeding brought against Open-Silicon based upon a claim of direct infringement of any patent (in effect as of the Effective Date) or copyright issued under the laws of United States, Canada, European Union, Iceland, Norway, Switzerland, India, Israel, Taiwan, Hong Kong, Japan, Australia, or New Zealand, or misappropriation of any trade secret recognized as such under the Uniform Trade Secret laws, arising from: (a) Open-Silicon’s or its supplier’s use of or compliance with Customer’s designs or specifications, or (b) any Customer-furnished Technology, and will pay all damages and costs finally awarded against Open-Silicon in connection with such claim.  Open-Silicon will: (i) promptly notify Customer in writing of any such suit or proceeding, (ii) provide Customer with sole control over the defense or settlement of any such claim or action; and (iii) provide reasonable information and assistance in the defense or settlement of any such claim or action. Open-Silicon may participate in any such suit or proceeding through counsel of its choice at Open-Silicon’s own expense; provided, that the costs associated with Open-Silicon’s counsel shall not be deemed damages or costs for purposes of Customer’s indemnity hereunder.  Customer shall obtain Open-Silicon’s prior written consent, which consent shall not be unreasonably withheld, to any settlement of any third party claim, action, suit or proceeding, except if the settlement is only for monetary damages and contains a full release of Open-Silicon from the claim.  Notwithstanding the foregoing, Customer reserves the right (but shall have no obligation) to cancel the Project giving rise to a third party claim (or a threat thereof), which may be subject to an indemnity obligation under this Section 14.2.

14.4         Exclusions from Indemnification by Customer .  Customer will not be liable for any expenses, damages, costs or losses to the extent arising out of or resulting from any suit or proceeding based upon a claim of intellectual property infringement that (a) the Services or Production Units alone and not in combination with any other product or service constitute a direct infringement of any patent (in effect as of the Effective Date) or copyright, or misappropriation of any trade secret recognized as such under the Uniform Trade Secret laws.

14.5         Entire Obligation; Exclusive Remedy.  The foregoing states the entire obligation and exclusive remedy of each of the parties hereto with respect to any alleged intellectual property infringement regarding any Product, Intellectual Property Right, or Service furnished hereunder.

15.                                EXPORT.

Customer will not export, either directly or indirectly, any Open-Silicon-furnished Technology or any Product or system incorporating such Product without first obtaining any required license or other approval from the Government of the country into which the technology or product is imported (“Host Government”) or the U.S. Department of Commerce or any other agency or department of the Host Government or the United States Government.

14

16.                                ELECTRONIC TRANSACTIONS.

16.1         General.   Subject to the terms and conditions of this Section 16.1, the parties agree to receive electronic documents and accept electronic signatures relating to transactions contemplated by this Agreement, including delivery releases, purchase orders, purchase order acknowledgments, invoices and other transactions as may be agreed by the parties from time to time.  Electronic documents and electronic signatures shall be a substitute for paper-based documents and signatures, and the legal validity of a transaction will not be denied on the ground that it is not in writing.  This Agreement may not be amended or terminated by these means.

16.2         Transmission of Electronic Documents.  All electronic documents shall be transmitted through the use of EDI, XML or other web-based transmission formats.  Electronic documents may be transmitted or received electronically directly by the parties or through designated third party communication network service providers with which either party may contract.  Each party agrees to designate all transmissions as confidential and protect all electronic documents from improper or unauthorized access in accordance with Section 12 (“Confidentiality and Publicity”).  Information contained in any electronic document or otherwise exchanged electronically between the parties shall be considered the confidential information of the disclosing party and shall be maintained in accordance with Section 12 (“Confidentiality and Publicity”).

16.3         “Electronic Signature” Defined.  For purposes of this Agreement, an electronic signature shall mean information or data in electronic form that is attached to or logically associated with an electronic document and executed or adopted with the intent to sign the electronic document.  An oral communication or a recording of an oral communication shall not qualify as an electronic signature.  Nothing in this Section 16.2 shall be construed to limit or otherwise affect the rights of either party to assert that an electronic signature is a forgery, is used without authority, or otherwise is invalid for reasons that would invalidate the effect of a signature in written form.

17.                                GOVERNING LAW.

This Agreement is to be construed and interpreted according to the laws of the State of Delaware, excluding its conflict of laws provisions that would require the application of the laws of another state. THE PROVISIONS OF THE UNITED NATIONS CONVENTION ON CONTRACTS FOR THE INTERNATIONAL SALE OF GOODS AND THE UNIFORM COMPUTER INFORMATION TRANSACTIONS ACT (UCITA) SHALL NOT APPLY TO THIS AGREEMENT.

18.                                MISCELLANEOUS.

18.1         Restricted Use.  Customer acknowledges and agrees that the Products are not designed, intended, or certified for use in components of systems intended for, or in relation to the operation of [***], or for any other application in which the failure of the Product could create a situation where [***] may occur, and Customer shall not use, sell, or otherwise distribute the Products for said uses.

15

18.2         Notices.   Unless otherwise stated herein, written notices shall be delivered by hand, mail, fax, or email (with contemporaneous delivery by one of the foregoing means) to the persons and at the addresses as set forth below (in the case of Open-Silicon), or as set forth on the signature page of the Agreement (in the case of Customer).  Either party may change its address for receipt of notice to the other party by delivering written notice of such change pursuant to this Section 18.2.

Open-Silicon, Inc.

490 N. McCarthy Blvd., Suite 220

Milpitas, CA 95035

Attn: Contract Management

18.3         Force Majeure.  Except for the obligation to pay any amounts when due, neither party will be liable for any failure to perform acts due to unforeseen circumstances or causes beyond the parties’ reasonable control. If any such circumstances occur, the affected party’s time for delivery or other performance will be extended for a period equal to the duration of the delay caused thereby, provided that the party affected by such circumstances or causes uses commercially reasonable efforts to mitigate the effect of such delay.  Either party may terminate this Agreement upon written notice if such circumstances or causes delay any party’s performance under this Agreement by a period of more than thirty (30) days.

18.4         Assignment.  This Agreement will be binding upon and inure to the benefit of the parties hereto and their permitted successors and assigns.  Notwithstanding the foregoing, neither this Agreement, nor any rights or obligations hereunder, may be assigned or otherwise transferred by either party without the prior written consent of the other party, provided, however, that either party may assign, without prior written consent all or any of its rights or delegate all or any of its obligations under this Agreement to a majority owned subsidiary of such party or to a third party in connection with merger or the sale of all or substantially all of the assets or business to which this Agreement relates.  Any other attempted assignment or transfer without prior written consent will be voidable at the option of the non-consenting party.

18.5         Subcontractors.   Customer acknowledges that in performing the Services Open-Silicon may use Subcontractors to design, manufacture and/or ship Products without Customer’s prior approval; provided that Open-Silicon shall remain fully responsible and liable for the performance of the Services and its other obligations under this Agreement, and any act or omission of Open-Silicon’s Subcontractors (other than Subcontractors designated by Customer in writing) shall constitute an act or omission of Open-Silicon, and any act or omission by an such Subcontractors (other than Subcontractors designated by Customer in writing) that would constitute a breach of the terms and conditions of this Agreement if it were an act or omission by Open-Silicon shall constitute a breach of this Agreement by Open-Silicon.  Notwithstanding the foregoing, in the event that the SOW identifies a specific Subcontractor to perform certain functions hereunder or requires that the Subcontractor for certain functions will be mutually agreed upon by the parties, Open-Silicon may not use another Subcontractor to perform such functions without obtaining Customer’s prior written approval therefor.

18.6         Counterparts.   This Agreement may be executed in multiple counterparts, each of which will be deemed to be an original and all of which will be deemed a single agreement.

18.7         Construction.  The headings provided in this Agreement are for convenience only and shall not be used in interpreting or construing this Agreement.  For purposes of this Agreement, the term, “including” means “including but not limited to”.

18.8         Independent Contractors.   The parties hereto are independent contractors.  Nothing in this Agreement will be construed to make the parties partners or joint venture or to make either party liable for the obligations, acts, or activities of the other.

18.9         Third Party Rights.  The provisions of this Agreement are intended solely for the benefit of Customer and Open-Silicon, and shall create no rights or obligations enforceable by any other party. Notwithstanding the foregoing, to the extent that a third party is licensed hereunder, such third party is a beneficiary of the provisions hereof that related to such licensed rights.

16

18.10       Rights and Remedies Cumulative.  Except as provided in Section 10 (“Limited Product Warranty; Disclaimer”), the parties’ rights and remedies under this Agreement are cumulative.  Each party acknowledges and agrees that an actual or threatened breach of any of the provisions contained in this Agreement may result in immediate, irreparable and continuing damage to the non-breaching party for which there may be no adequate remedy at law, and the non-breaching party may apply to any court of competent jurisdiction for specific performance or injunctive relief to enforce or prevent any breach of the provisions of this Agreement.

18.11       Severability; Limitations Period.  If any provision of this Agreement becomes or is declared by a court of competent jurisdiction to be illegal, invalid or unenforceable for any reason, then such provision will be enforced to the maximum extent permissible under the circumstances so as to effect the intent of the parties and the economic effect of the Agreement.  Neither the legality, validity or enforceability of the remaining provisions hereof nor the legality, validity, or enforceability of the provision at issue in other circumstances will otherwise be affected or impaired thereby, and the remainder of the provisions of this Agreement will remain in full force and effect.  The parties will replace any unenforceable provision with a valid, legal and enforceable provision that most early achieves the economic effect of the unenforceable provision.  Without limiting the generality of the foregoing, the parties agree that Section 11 (“Limitation of Liability”) will remain in effect notwithstanding the illegality, invalidity, unenforceability, or failure of the essential purpose of any provision in Section 10 (“Limited Product Warranty; Disclaimer”).

18.12       Entire Agreement.   This Agreement, including the exhibits hereto and each SOW, contains the entire understanding between Customer and Open-Silicon with respect to the subject matter hereof and merges and supersedes all prior and contemporaneous agreements, dealings and negotiations.  Any modification, alteration, or amendment to this Agreement will not be effective unless made in writing, dated and signed by duly authorized representatives of both parties. All rights and remedies, whether conferred hereunder, or by operation of law, will be cumulative and may be exercised singularly or concurrently.   Failure by either party to enforce a term will not be deemed a waiver of future enforcement of that or any other term.  The following Exhibits are hereby incorporated herein by this reference:  Exhibit A (“Statement of Work”), Exhibit B-1 (“Prototype Approval Form”), Exhibit B-2 (“Release to Production Form”), Exhibit C (“Engineering Change Order Process”), Exhibit D (“Milestone Acknowledgement Letter”), and Exhibit E (“Die Banking”). In the event of a conflict between the terms of this Agreement and any exhibit, the terms of this Agreement will govern.  In the event of a conflict between Exhibit A and a change order executed by parties, the change order will govern.

17

IN WITNESS WHEREOF, the parties have caused their duly authorized representatives to enter into this Agreement, effective as of the Effective Date.

18

Exhibit A

STATEMENT OF WORK

Netlist Inc

[***]

PROJECT: [***] ASICs

[***]

DESIGN, PROTOTYPE DELIVERY & PRODUCTION

This Statement of Work (“SOW”) is entered into as Exhibit A to the Open-Silicon Inc. ASIC Design and Production Agreement (the “Agreement”) and is attached thereto and incorporated therein; and in the event the Agreement is not executed, the initial draft of the Agreement is attached hereto and incorporated herein and shall serve to govern the terms and conditions of the relationship until such time (if at all) such Agreement is executed. This document dated [***], between Open-Silicon, Inc. (“Open-Silicon”) and Netlist Inc., (“Customer”), is for the ASIC project(s) commonly referred to by Customer as [***], and commonly referred to by Open-Silicon as [***] and [***] respectively (the “Project”).

This SOW defines the project scope for the above mentioned Project. This document describes the Project details, activities, deliverables, milestones, assumptions, and pricing for the Project.

This document represents the complete set of services and deliverables provided by Open-Silicon. Services and deliverables [***] will [***] without [***] by [***] and may be [***].

The obligations of Open-Silicon and Customer under this Agreement are completely independent of any obligations existing under any other agreement between Open-Silicon and Customer, with the exception of the Agreement noted above.

1.                                       DEFINITION OF TERMS

The terms used herein are defined as follows:

·                   “ will define ”: party will provide technical data, requirements or specifications to enable the other party to fulfill project tasks and deliverables.

·                   “ will confirm ”: party to positively affirm technical data, requirements or specifications proposed by other party to fulfill project tasks and deliverables. Except where noted in the Agreement, affirmation may be given through email or through other digital authorization methods.

·                   “ will acquire ” or “ will obtain ”: party will obtain for the purposes of fulfilling project tasks and deliverables [***].

·                   “ will perform ”: party will complete as part of project tasks, with [***] defined.

·                   “ will manufacture”: party will manufacture, or arrange to manufacture, materials for the purposes of fulfilling project tasks and deliverables, with [***] defined.

·                   “ will present for review ”: party will deliver for the sole purpose of review by the other party. In this case, material may be presented on supplier premises [***]. In any case, the materials presented for review remain the property of [***] or [***].

·                   “ will consult ”: party will provide [***] guidance for the purpose of assisting the other party to complete project tasks and deliverables. Party [***] as a result of such guidance.

·                   “ will sign off ”: party will acknowledge acceptance of deliverable and the technical data contained within, confirming the data meets the goals of the project.  Except where noted in the Agreement, acknowledgement may be given through email or through other digital authorization methods.

·                   “ will provide ” or “ will deliver ”: party will provide to the other party as a project deliverable.  This may include reports, IP, manufactured articles or material goods. Ownership of intellectual property underlying all project deliverables is not defined in this document. Ownership and usage rights of intellectual property and material goods generated by [***] are defined in the Agreement. Ownership and usage rights of intellectual property generated by [***] are defined in [***] or equivalent document provided by [***].

2.                                       PROJECT SCOPE

Open-Silicon is contracted to provide a quantity of tested packaged prototype devices to Customer for the [***] (Netlist Document 309-0001-42) and [***] (Netlist Document 309-0002-42) designs. Working from [***] and [***], Open-Silicon will [***] and [***] for release to an [***] at a [***], prepare [***] and [***], and design and fabricate [***] for the sample units. Following Customer approval of the prototype devices, [***], and [***], Open-Silicon will provide production silicon in accordance with Customer purchase orders, as further described in the Agreement.

2.1        PRODUCT PROPOSAL

The information provided in this section is subject to [***]. Some [***] may be [***]. [***] reserves the right to [***] below due to changes in [***]. Changes should be [***] by ECO, and may impact the [***] noted in this document.

3

4

2.1.2                      Memory Types

2.1.2.1        (Insert additional rows as needed)

2.1.4                      Foundry Setup

2.1.4.1

*Yield must follow the [***] used by [***] to predict production [***] otherwise [***] will be adjusted.

5

2.1.5                      IP List

2.1.5.1        IP Provided by [***]

[***] will provide the following [***], subject to [***] in [***] of the Agreement.

2.1.5.2        IP Notes

·                   All IP is characterized for the process technology described in section 2.1.4.

·                   Unless otherwise stated, all IP includes [***] provided by [***] and [***] starting on the date on which [***] was received.

·                   For the package of IP of provided by [***], the [***] can be [***]. There is [***] to [***] for the following products: [***]

·                   Open-Silicon recommends that [***] is [***] until the silicon is [***]. Extension of [***] is possible with the [***] commencing on the [***].

·                   [***] are not included for [***] and can be provided [***].

·                   For [***] noted in the table above, [***] may initiate work with a [***] using [***] (if applicable). Over the course of development for [***], the [***] will provide specifications and deliverables, providing detail in addition to the specifications noted in this SOW. [***] is responsible for reviewing and signing off on such interim deliverables, up to and including [***]. [***] will facilitate the reviews for these deliverables. [***] acknowledges that [***] during this process. [***] that [***] relative to the [***] should be [***] through an ECO addendum to this SOW.

2.1.5.3        IP Provided by Customer

·                   [***] is responsible for all the IP support and arrangement of all the integration reviews and sign-offs from [***] for the [***]. This should include at least one [***] review during the Explore Phase, and a final review during the Implement Phase to sign-off on the [***].

2.1.5.4        Limitations in IP Usage

·                   IP as [***] is for [***] and [***] unless otherwise stated.

6

2.1.6                      TEST and DFT

2.1.6.1        Test Hardware Summary

2.1.6.2        Subsystem Test Summary

2.1.6.3        DFT Structures — [***] Provided

Note: [***] to provide [***] to [***].

7

2.1.6.4        DFT Structures — [***] Provided

2.1.6.5        Functional Test Patterns — [***] Provided

2.1.6.6        Test List — Full Packaged Test

*If partial scan is implemented then test coverage may be lower than desired. [***] may need to provide [***] to meet [***] since [***] had expected to [***]. Note that there is no [***] included in this SOW for [***].

2.1.6.7  Test Effort

The SOW assumes [***] and [***] on the [***] for the purpose of [***] and [***]. The SOW also assumes [***] of effort on-tester and [***] of effort off-tester on the [***] for the purpose of [***] and [***]. [***] test will be performed at [***] or a [***].

8

2.1.7                      Design

2.1.7.1 Design Features Summary

[***] agrees that design efforts will [***], but will [***] at [***] and the [***] will need to be [***]. If [***] is necessitated due to [***] related to [***] between the analyze, explore, and implement drops there will be [***].

2.1.7.2 Design Tool and Signoff Responsibility

*If a [***] cannot be provided, [***] will need to [***].

9

2.1.8                      Packaging

2.1.8.1 Packaging Summary

The NRE includes a [***]. Device assembly will be performed at [***] or [***].

2.1.8.2 Special Package Treatment Options

[***] may select special treatment options for [***]. Some items may involve [***]. If these options are [***], [***] will [***] that attempt to [***] listed elsewhere in this document.

2.1.8.3 Package Extraction Options

[***] may select extraction options for package design. [***] these items entail [***], which is [***].

10

2.1.8.4 [***] will make [***] design available to [***] so that [***] can [***] package models.

2.1.9                     [***] anticipates the need to create some reasonably small number [***] in order to facilitate [***] on this design. While not [***] in this agreement, [***] agrees that it will [***] for the design and implementation [***] as will be determined to be necessary to [***].

2.1.10               Product Qualification

Product qualification is [***], with [***] defined in section [***]. In addition, the [***] will need [***] the quantity of [***] required for this task.

2.1.10.1 Product Qualification Test List